Laserfiche WebLink
b. Upon approval by EPA. Respondent shall implement the Pahala <br /> Community Cesspool Closure Project in accordance with the provisions and schedule set forth in <br /> the Pahala Implementation Plan. <br /> C. Na'alehu Community Cesspool Closure Project <br /> 33. Respondent shall fully and properly comply with the SDWA with respect to the <br /> Na'alehu Community Cesspools identified in Paragraph 22. by providing wastewater treatment <br /> that is protective of surface water and underground sources of drinking water for 194 properties <br /> in Na'alehu. including 164 properties that are currently connected to the Na'alehu Community <br /> Cesspools, and closing the Na'alehu Community Cesspools.As soon as practicable. but no later <br /> than the deadlines specified herein. Respondent shall complete the following milestones to <br /> achieve compliance with the SDWA: <br /> a. Na'alehu Implementation Plan. Within 60 days of receiving written <br /> approval of the EID prepared pursuant to Paragraph 31.c, Respondent shall submit for EPA <br /> approval an implementation plan for the selected project prepared by a licensed professional <br /> engineer identifying the steps required to design and implement the selected project for Na'alehu <br /> (Na'alehu Implementation Plan). Respondent must follow applicable federal, Hawaii state.and <br /> local requirements for design. construction,and operation of such facilities and shall diligently <br /> pursue all necessary permits and approvals. The Na'alehu Implementation Plan shall include <br /> steps for obtaining all required permits and approvals.The Na'alehu Implementation Plan shall <br /> include a schedule and completion dates for each step required to implement the selected <br /> alternative, provide wastewater services for 194 properties.and to close the Na'alehu <br /> Community Cesspools no later than December 31,2027. <br /> 9 <br />